Terms of Service

Terms of Service

Last Updated: August 2026



1. Platform Role & Non-Contractor Status



Pave A Lot ("Company," "we," "us," or "our") operates solely as an independent matchmaking, informational directory, and project coordination platform. We assist property owners, managers, and authorized representatives ("Users" or "you") by providing project specifications to independent, third-party paving, sealcoating, asphalt, striping, concrete, and maintenance contractors ("Service Providers").



  • No Phone Number Transfers: Pave A Lot maintains strict data privacy. We do not sell, share, rent, or transfer your phone number or mobile identity to Service Providers or external third parties. All mobile contact remains strictly between you and Pave A Lot.


  • No Construction Services: Pave A Lot is not a general contractor, sub-contractor, specialty trade contractor, or construction project manager. We do not provide architectural, engineering, or physical labor services.


  • No Site Control: We do not direct, supervise, schedule, control, inspect, or manage the means, methods, techniques, sequences, job-site safety protocols, or execution of any work performed by Service Providers.


2. Independent Service Provider Relationship & User Verification



All Service Providers listed on or referred through the platform are independent business entities and not employees, agents, partners, or joint venturers of Pave A Lot.



  • Separate Contracts: Any quote, scope of work, agreement, change order, or physical service contract is entered into directly and exclusively between you and the Service Provider.


  • Mandatory User Due Diligence: Pave A Lot does not verify, validate, or guarantee any Service Provider's state or municipal trade licenses, bonding, commercial general liability coverage, workers' compensation insurance, or regulatory standing. You assume sole responsibility for verifying all credentials, obtaining certificates of insurance (naming you as an additional insured if required), and pulling necessary municipal permits prior to authorizing work.


3. Zero-Payment Processing & Financial Disclaimers



Pave A Lot does not bill, invoice, collect, hold, escrow, process, or mediate payments between Users and Service Providers.



  • Direct Transactions: All financial transactions—including deposits, progress payments, change orders, retainers, and final settlement balances—are executed directly between you and the Service Provider.


  • Payment & Performance Disputes: Pave A Lot is not a party to your payment arrangements and disclaims all liability for pricing changes, refund requests, non-performance, double billing, or disputed deposit returns.


  • Mechanic's Liens & Encumbrances: Pave A Lot bears no responsibility or liability for statutory mechanic's liens, materialman's liens, stop notices, or other legal encumbrances placed against your real property by Service Providers, sub-tier contractors, labor forces, or material suppliers.


4. Inquiries, Leads, and Estimates



Submitting a project request via our digital forms, website, email, or telephone systems acts solely as an authorization for Pave A Lot to review your non-confidential project requirements (e.g., job type, scope, general vicinity) to locate available independent Service Providers.



  • Phone Number Protection: Your telephone number is strictly excluded from project data transmitted to Service Providers. Service Providers will not receive your phone number from us. Match confirmations, scheduling updates, and contractor details will be communicated to you solely by Pave A Lot.


  • No Contractual Guarantees: Submissions do not constitute a formal construction contract, nor do they guarantee that an independent contractor will accept or bid on your project.


  • Non-Binding Estimates: Any preliminary price ranges or timelines communicated prior to a contractor's physical site inspection are non-binding estimates and remain subject to change following direct assessment.


5. Mobile Messaging & SMS Communications (A2P 10DLC Compliance)



By providing your phone number and checking the separate SMS opt-in box on our web forms, you provide express written consent to receive operational and transactional SMS/MMS text messages directly from Pave A Lot.



  • Program Description: Text messages are limited to transactional service notices, project match notifications, contractor detail confirmations, and customer care follow-ups regarding your request. Messages originate exclusively from Pave A Lot. We do not transfer your number to Service Providers, nor do we authorize third parties to contact you. Opting in to receive text messages is completely voluntary and is never a condition of submitting a project inquiry or purchasing any goods or services.


  • Message Frequency: Message frequency varies based on project activity and the status of your inquiry.


  • Cost Disclosure: Message and data rates may apply depending on your mobile carrier and wireless plan.


  • Opt-Out (STOP): You can revoke consent and cancel text notifications at any time. Simply reply STOP to any message received from us. You will receive one final text message confirming that you have been unsubscribed. After this confirmation, you will receive no further text messages unless you submit a new opt-in request.


  • Help & Support (HELP): For assistance or inquiries, reply HELP to any message, contact customer support at (469) 826-4567, or email support@pavealot.online.


  • Carrier Liability Disclaimer: Mobile wireless carriers (including AT&T, T-Mobile, and Verizon) are not liable for delayed or undelivered messages.


  • Strict Data Privacy: No mobile information, phone numbers, opt-in data, or SMS consent will be shared, sold, rented, or leased to third parties, contractors, or affiliates for marketing, promotional, or lead-generation purposes. All text messaging consent applies solely to Pave A Lot.


6. Disclaimer of Warranties



THE PLATFORM, REFERRALS, AND INFORMATION ARE PROVIDED STRICTLY ON AN "AS IS" AND "AS AVAILABLE" BASIS. TO THE MAXIMUM EXTENT PERMITTED BY LAW, PAVE A LOT DISCLAIMS ALL WARRANTIES, EXPRESS, IMPLIED, STATUTORY, OR OTHERWISE, INCLUDING:



  • Merchantability, structural durability, safety, aesthetic finish, or fitness for a particular purpose of any asphalt, sealcoating, concrete, or drainage project.


  • Accuracy of site plans, square footage measurements, material thickness specs, or engineering layouts.


  • Compliance with local building codes, environmental/runoff regulations, fire marshal lane requirements, or the Americans with Disabilities Act (ADA).


  • The honesty, reliability, qualifications, background, or creditworthiness of any Service Provider.


7. Limitation of Liability



TO THE FULLEST EXTENT PERMITTED BY LAW, UNDER NO CIRCUMSTANCES SHALL PAVE A LOT, ITS OFFICERS, DIRECTORS, EMPLOYEES, OR AFFILIATES BE LIABLE FOR ANY DIRECT, INDIRECT, INCIDENTAL, CONSEQUENTIAL, SPECIAL, EXEMPLARY, OR PUNITIVE DAMAGES ARISING FROM:



  • Real property damage, sub-base failure, structural cracking, underground utility damage, chemical runoff, or environmental hazards.


  • Bodily injury, workplace incidents, or wrongful death occurring on or adjacent to your property.


  • Contractor abandonment, delays, incomplete scopes of work, or defective workmanship.


  • Code citations, municipal stop-work orders, fines, or accessibility lawsuits (e.g., ADA compliance actions).


IF ANY RESTRICTION IN THIS SECTION IS HELD UNENFORCEABLE, PAVE A LOT’S TOTAL AGGREGATE LIABILITY ARISING FROM OR RELATING TO YOUR USE OF THE PLATFORM OR SERVICES SHALL NOT EXCEED $100.00 USD.



8. Indemnification



You agree to defend, indemnify, and hold harmless Pave A Lot, its owners, directors, officers, employees, and agents against any third-party claims, demands, liabilities, damages, regulatory fines, and expenses (including reasonable attorneys’ fees and court costs) resulting from:



  • Your contractual engagement, financial transactions, or disputes with any Service Provider.


  • Physical work, property modifications, damages, or injuries occurring at your job site.


  • Your failure to verify contractor licenses, permits, or insurance.


  • Your violation of any applicable federal, state, or municipal law.


9. Mandatory Arbitration & Class Action Waiver



Any dispute, claim, or controversy arising out of or relating to these Terms, platform usage, or referral services shall be resolved exclusively by final and binding arbitration administered by the American Arbitration Association (AAA) under its Commercial Arbitration Rules.



  • Venue: Arbitration proceedings shall occur in Collin County or Dallas County, Texas.


  • Class Action Waiver: ALL CLAIMS MUST BE BROUGHT IN AN INDIVIDUAL CAPACITY AND NOT AS A PLAINTIFF, CLASS REPRESENTATIVE, OR CLASS MEMBER IN ANY PURPORTED CLASS, COLLECTIVE, OR REPRESENTATIVE PROCEEDING.


10. Governing Law & Severability



These Terms are governed by the laws of the State of Texas, without regard to conflict of law principles. If any provision of these Terms is deemed invalid or unenforceable, that provision will be severed, and the remaining provisions will continue in full force and effect.



11. Contact Information



If you have any questions regarding these Terms, please contact us at:



  • Phone: (469) 826-4567


  • Email: support@pavealot.online


  • Website: www.pavealot.online